Terms and conditions

GMP Property Services > Terms and conditions

AGREEMENT TO OUR LEGAL TERMS

We are GMP Property Services (‘Company‘, ‘we‘, ‘us‘, or ‘our‘), a company registered in the United Kingdom at 71-75 Shelton Street Covent Garden, London.

We operate the website https://gmppropertyservices.co.uk/ (the ‘Site‘), as well as any other related products and services that refer or link to these legal terms (the ‘Legal Terms‘) (collectively, the ‘Services‘).

Our approach to providing the highest quality maintenance services is very simple – it’s all about trust, competence and integrity. Our general maintenance, renovation and fully skilled decoration services provides a truly exceptional service across London and the surrounding areas. GMP is only one phone call away – let us be your total property solution!

You can contact us by phone at 02034888198 | 07479566650, email at [email protected], or by mail to 71-75 Shelton Street Covent Garden, London, United Kingdom.

These Legal Terms constitute a legally binding agreement made between you, whether personally or on behalf of an entity (‘you‘), and GMP Property Services, concerning your access to and use of the Services. You agree that by accessing the Services, you have read, understood, and agreed to be bound by all of these Legal Terms. IF YOU DO NOT AGREE WITH ALL OF THESE LEGAL TERMS, THEN YOU ARE EXPRESSLY PROHIBITED FROM USING THE SERVICES AND YOU MUST DISCONTINUE USE IMMEDIATELY.

We will provide you with prior notice of any scheduled changes to the Services you are using. The modified Legal Terms will become effective upon posting or notifying you by __________, as stated in the email message. By continuing to use the Services after the effective date of any changes, you agree to be bound by the modified terms.

The Services are intended for users who are at least 18 years old. Persons under the age of 18 are not permitted to use or register for the Services.

We recommend that you print a copy of these Legal Terms for your records.

 

TABLE OF CONTENTS

 

  1. OUR SERVICES

By using our services, you certify that you have read and reviewed this agreement and that you agree to comply with the terms. If you do not want to be bound by the terms of this Agreement, you are advised to stop using the website accordingly; GMP only grants use and access to our website, products and services to those who have accepted its term. Services from other locations do so on their own initiative and are solely responsible for compliance with local laws, if and to the extent local laws are applicable.

 

  1. INTELLECTUAL PROPERTY RIGHTS

Our intellectual property

We are the sole owner / licensee of all intellectual property rights in our materials, products and services, including all source code, databases, functionality, software, website designs, audio, video, text, photographs, and graphics in the Services (collectively, the ‘Content’), as well as all copy rights,trade secrets, trademarks, patents, service marks, and logos contained therein (the ‘Marks’).

Your use of our Services

As a user of this website, you may be asked to register with us and provide private information. You will be solely responsible in ensuring accuracy in the information provided. You will be responsible for all activities that occur under your account or password.

We have a team of experts whom understand local regulations and codes. Our team of builders, architects, engineers, consultants and designers will help complete projects to the best of standards.

By you accepting out terms you acknowledge the following;

  1. Terms and conditions may only be amended with the consent of both parties in writing
  2. Client accepts and acknowledges that any information that is supplied to the client by the contractor for the purpose of providing a quotation remains the property of the contractor and must not be forwarded to any other party to submit quotation for works. If by any means the Client fails to comply with this clause, the Contractor reserves all rights to charge the Client for time taken to prepare for quotation/ information. Documentations supplied
  3. Client acknowledges that in the event that the supply of works/Materials/ Equipments requested exceeds the client’s credit limit and/or the account exceeds payment terms, Contract can reserve the right to refuse delivery.
  4. Any proposed change to the Scope of works requested by Client must be made in writing to the Contractor. Additional charges may incur.

 

  1. CHANGE IN CONTROL

Client is obliged to give the Contractor not less than fourteen ( 14) days prior to written notice of any proposed change of ownership that the client/ and or any other change in Clients details ( changes in name, address, contact number business practice etc)

Client at all time shall be liable for any lose incurred by the Contractor as a result of the Clients failure to comply with the clause.

 

  1. MATERIALS

Only suitable new Materials to be used

Demolished Materials shall remain within the Clients property, Contractors materials which are brought to the site shall remain the property of the Contractor.

Agreement between the Client and the Contractor shall be as followed;

  1. Client has paid the Contractor all amounts owed to the Contractor
  2. Client has met all their obligations to the Contractor
  3. Until ownership has been passed to the Client, any fixtured materials must return to the contractor
  4. Client holds insurance of the materials on trust for the Contractor and must pay the Contractor the proceeds of any insurance in the event of the Materials being lost, damaged or destroyed.
  5. Client must not sell, dispose or otherwise part from the possession of the materials for then the Client must hold the proceeds of any such act on trust for the Contractor and must pay or deliver the proceeds to the Contractor on demand
  6. Client should not at any time during the project convert or process the Materials or intermix them with other goods, if the Client does so then the Client holds the resulting product on trust for the benefit of the Contractor and must sell, dispose of the returns which results in product to the Contractor.
  7. Client can not charge nor give away any interest in the materials whilst they remain property of the Contractor
  8. Contractor may commence in recovering the price of the materials sold as of the ownership of the materials has not passed to the Client.

 

  1. PURCHASES AND PAYMENT

We accept the following forms of payment:

– PayPal

– American Express

– Mastercard

– Visa

You agree to provide current, complete, and accurate purchase and account information for all purchases made via the Services. You further agree to promptly update account and payment information, including email address, payment method, and payment card expiration date, so that we can complete your transactions and contact you as needed. Sales tax will be added to the price of purchases as deemed required by us. We may change prices at any time. All payments shall be in Starlings.

Client accepts and acknowledges that Contractor’s quotation or estimate includes solely the scope of works expressed and described therein. Client accepts that additional works may be required and will be charged depending on the variations of ;

  1. Works/Equipments which are supplied is requested
  2. Additional works are required due to the discovery of hidden/ unidentifiable difficulties ( poor weather conditions, limitation of accessing site, availability of machinery, safety considerations, prerequisite work by any third parties not being completed, change of design, hard rock barriers below the surface, iron reinforcing rods in concrete, hidden pipes, wiring, obscured building defects etc)
  3. Delays outside the Contractors control
  4. Increase in cost of labor or materials which are beyond the Contract’s control.

We require 10% of the total price booking fee, 30% at the start of the project, 30% during the project and the final 30% once the project has been completed.

If we incur any additional costs because of the following;

  1. Changes to the works which you have requested,
  2. Information which you have provided us with is not right
  3. If unexpected things have incurred which are outside of out control we will change the price.

This could take place before the works have started or during the works. We will notify you and you are required to make payments within 14 days of out notice.

Preliminary site inspections shall be made by the Contractor in order to provide Client with a quotation/estimate. In the event that the site has restricted accessed i.e Furnishings and other obstacles, this will have an effect on the Contractor’s ability to provide an accurate quotation. The client therefore accepts that additional charges may incur.

Contractor is prepared on the basis that all works shall be undertaken during the Contractor’s normal working hours however in the event that the client requires the Contractor to work outside its normal hours ( including public holidays, extended hours, weekends) then the contractor reserves the right to charge the client for additional labor costs.

You agree to pay all charges at the prices then in effect for your purchases and any applicable shipping fees, and you authorize us to charge your chosen payment provider for any such amounts upon placing your order.

We reserve the right to correct any errors or mistakes in pricing, even if we have already requested or received payment.

We reserve the right to refuse any order placed through the Services. We may, in our sole discretion, limit or cancel quantities purchased per person, per household, or per order. These restrictions may include orders placed by or under the same customer account, the same payment method, and/or orders that use the same billing or shipping address. We reserve the right to limit or prohibit orders that, in our sole judgment, appear to be placed by dealers, resellers, or distributors.

If payment of invoices is not received by its due date, we reserve the right to recover all and any costs, commissions, fees or disbursements incurred for the collection of the outstanding payment including those which may be incurred by using a debt collection agency, howsoever incurred.

 

  1. DISPUTE RESOLUTION

If any dispute arises between both parties during the the project then either party shall send to the other party a notice of dispute in writing identifying and providing details of the dispute. This should be done within fourteen (14) days after service of a notice dispute, the parties shall confer at least once, to attempt and resolve the issue.

If at any case this takes place each party shall be represented by a person having authority to agree to a resolution of dispute. In such event that the dispute can not be resolved than either party may by further notice in writing delivered by hand or sent via email to the other party.

 

  1. POLICY

All sales are final and no refund will be issued.

 

  1. COMPLIANCE WITH THE LAWS

Client and Contractor shall comply with the provisions of all statutes, regulations and bylaws of the government, local and public authorities that may be applicable to the works.

Client shall obtain all licenses, approvals, applications and permits that may be required for the works, which have not be included in the project documents provided by the contractor.

Client agrees that the site will comply with all work health and safety laws relating to the building/ construction sites/

 

  1. USER REPRESENTATIONS

By using the Services, you represent and warrant that:

(1) you have the legal capacity and you agree to comply with these Legal Terms;

(2) you are not a minor in the jurisdiction in which you reside

; (3) you will not access the Services through automated or non-human means, whether through a both, script or otherwise; (4) you will not use the Services for any illegal or unauthorized purpose; and (5) your use of the Services will not violate any applicable law or regulation.

If you provide any information that is untrue, inaccurate, not current, or incomplete, we have the right to suspend or terminate your account and refuse any and all current or future use of the Services (or any portion thereof).

 

  1. PROHIBITED ACTIVITIES

You may not access or use the Services for any purpose other than that for which we make the Services available. The Services may not be used in connection with any commercial endeavors except those that are specifically endorsed or approved by us.

As a user of the Services, you agree not to:

Systematically retrieve data or other content from the Services to create or compile, directly or indirectly, a collection, compilation, database, or directory without written permission from us.

Trick, defraud, or mislead us and other users, especially in any attempt to learn sensitive account information such as user passwords.

Circumvent, disable, or otherwise interfere with security-related features of the Services, including features that prevent or restrict the use or copying of any Content or enforce limitations on the use of the Services and/or the Content contained therein.

Disparage, tarnish, or otherwise harm, in our opinion, us and/or the Services.

Use any information obtained from the Services in order to harass, abuse, or harm another person.

Make improper use of our support services or submit false reports of abuse or misconduct.

Use the Services in a manner inconsistent with any applicable laws or regulations.

Engage in unauthorised framing of or linking to the Services.

Upload or transmit (or attempt to upload or to transmit) viruses, Trojan horses, or other material, including excessive use of capital letters and spamming(continuous posting of repetitive text), that interferes with any party’s uninterrupted use and enjoyment of the Services or modifies, impairs, disrupts, alters, or interferes with the use, features, functions, operation, or maintenance of the Services.

Engage in any automated use of the system, such as using scripts to send comments or messages, or using any data mining, robots, or similar data gathering and extraction tools.

Delete the copyright or other proprietary rights notice from any Content.

Attempt to impersonate another user or person or use the username of another user.

Upload or transmit (or attempt to upload or to transmit) any material that actsas a passive or active information collection or transmission mechanism, including without limitation, clear graphics interchange formats (‘gifs’), 1×1pixels, web bugs, cookies, or other similar devices (sometimes referred to as ‘spyware’ or ‘passive collection mechanisms’ or ‘pcms’).

Interfere with, disrupt, or create an undue burden on the Services or the networks or services connected to the Services.

Harass, annoy, intimidate, or threaten any of our employees or agents engaged in providing any portion of the Services to you.

Attempt to bypass any measures of the Services designed to prevent or restrict access to the Services, or any portion of the Services.

Copy or adapt the Services’ software, including but not limited to Flash, PHP,HTML, JavaScript, or other code.

Except as permitted by applicable law, decipher, decompile, disassemble, or reverse engineer any of the software comprising or in any way making up apart of the Services.

Except as may be the result of standard search engine or Internet browser usage, use, launch, develop, or distribute any automated system, including without limitation, any spider, robot, cheat utility, scraper, or offline reader that accesses the Services, or use or launch any unauthorised script or other software.

Use a buying agent or purchasing agent to make purchases on the Services.

Make any unauthorised use of the Services, including collecting usernames and/or email addresses of users by electronic or other means for the purpose of sending unsolicited email, or creating user accounts by automated means or under false pretences.

Use the Services as part of any effort to compete with us or otherwise use the Services and/or the Content for any revenue-generating endeavour or commercial enterprise.

Use the Services to advertise or offer to sell goods and services.

 

  1. CONTRIBUTION LICENCE

By posting your Contributios to any part of the Services

, you automatically grant, and you represent and warrant that you have the right to grant, to us an unrestricted, unlimited, irrevocable, perpetual, non-exclusive, transferable, royalty-free, fully-paid, worldwide right, and licence to host, use, copy, reproduce, disclose, sell, resell, publish, broadcast, retitle, archive, store, cache, publicly perform, publicly display,reformat, translate, transmit, excerpt (in whole or in part), and distribute such Contributions (including, without limitation, your image and voice) for any purpose,

commercial, advertising, or otherwise, and to prepare derivative works of, orincorporate into other works, such Contributions, and grant and authorisesublicences of the foregoing. The use and distribution may occur in any mediaformats and through any media channels.

This licence will apply to any form, media, or technology now known or hereafterdeveloped, and includes our use of your name, company name, and franchise name,as applicable, and any of the trademarks, service marks, trade names, logos, andpersonal and commercial images you provide. You waive all moral rights in yourContributions, and you warrant that moral rights have not otherwise been asserted in your Contributions.

We do not assert any ownership over your Contributions. You retain full ownership off all of your Contributions and any intellectual property rights or other proprietary rights associated with your Contributions. We are not liable for any statements orrepresentations in your Contributions provided by you in any area on the Services. You are solely responsible for your Contributions to the Services and you expressly agree to exonerate us from any and all responsibility and to refrain from any legal action against us regarding your Contributions.

We have the right, in our sole and absolute discretion, (1) to edit, redact, or otherwise change any Contributions; (2) to re-categories any Contributions to place them in more appropriate locations on the Services; and (3) to pre-screen or delete any Contributions at any time and for any reason, without notice. We have no obligation to monitor your Contributions.

 

  1. GUIDELINES FOR REVIEWS

We may provide you areas on the Services to leave reviews or ratings. When postinga review, you must comply with the following criteria: (1) you should have firsthand experience with the person/entity being reviewed; (2) your reviews should not contain offensive profanity, or abusive, racist, offensive, or hateful language; (3) your reviews should not contain discriminatory references based on religion, race, gender, national origin, age, marital status, sexual orientation, or disability; (4) your reviews should not contain references to illegal activity; (5) you should not be affiliated with competitors if posting negative reviews; (6) you should not make any conclusions as to the legality of conduct; (7) you may not post any false or misleading statements; and (8) you may not organise a campaign encouraging others to post reviews, whether positive or negative.

We may accept, reject, or remove reviews in our sole discretion. We have absolutely no obligation to screen reviews or to delete reviews, even if anyone considers reviews objectionable or inaccurate. Reviews are not endorsed by us, and do not necessarily represent our opinions or the views of any of our affiliates or partners. We do not assume liability for any review or for any claims, liabilities, or losses resulting from any review. By posting a review, you hereby grant to us a perpetual, non-exclusive, worldwide, royalty-free, fully paid, assignable, and sub licensable right and license to reproduce, modify, translate, transmit by any means, display, perform, and/or distribute all content relating to review.

 

  1. SERVICES MANAGEMENT

We reserve the right, but not the obligation, to: (1) monitor the Services for violations of these Legal Terms; (2) take appropriate legal action against anyone who, in our sole discretion, violates the law or these Legal Terms, including without limitation,reporting such user to law enforcement authorities; (3) in our sole discretion andwithout limitation, refuse, restrict access to, limit the availability of, or disable (to theextent technologically feasible) any of your Contributions or any portion thereof; (4) in our sole discretion and without limitation, notice, or liability, to remove from the Services or otherwise disable all files and content that are excessive in size or are in any way burdensome to our systems; and (5) otherwise manage the Services in amanner designed to protect our rights and property and to facilitate the properfunctioning of the Services.

 

  1. PRIVACY POLICY

We care about data privacy and security. By using the Services, you agree to bebound by our Privacy Policy posted on the Services, which is incorporated into these Legal Terms. Please be advised the Services are hosted in the United Kingdom. If you access the Services from any other region of the world with laws or other requirements governing personal data collection, use, or disclosure that differ from applicable laws in the United Kingdom, then through your continued use of the Services, you are transferring your data to the United Kingdom, and you expressly consent to have your data transferred to and processed in the United Kingdom.

 

  1. COPYRIGHT INFRINGEMENTS

We respect the intellectual property rights of others. If you believe that any materialavailable on or through the Services infringes upon any copyright you own or control,please immediately notify us using the contact information provided below (a’Notification’). A copy of your Notification will be sent to the person who posted orstored the material addressed in the Notification. Please be advised that pursuant toapplicable law you may be held liable for damages if you make materialmisrepresentations in a Notification. Thus, if you are not sure that material located onor linked to by the Services infringes your copyright, you should consider first contacting an attorney.

 

  1. TERM AND TERMINATION

These Legal Terms shall remain in full force and effect while you use the Services. WITHOUT LIMITING ANY OTHER PROVISION OF THESE LEGAL TERMS, WERESERVE THE RIGHT TO, IN OUR SOLE DISCRETION AND WITHOUT NOTICEOR LIABILITY, DENY ACCESS TO AND USE OF THE SERVICES (INCLUDINGBLOCKING CERTAIN IP ADDRESSES), TO ANY PERSON FOR ANY REASON ORFOR NO REASON, INCLUDING WITHOUT LIMITATION FOR BREACH OF ANYREPRESENTATION, WARRANTY, OR COVENANT CONTAINED IN THESE LEGALTERMS OR OF ANY APPLICABLE LAW OR REGULATION. WE MAY TERMINATEYOUR USE OR PARTICIPATION IN THE SERVICES OR DELETE

ANY CONTENTOR INFORMATION THAT YOU POSTED AT ANY TIME, WITHOUT WARNING, INOUR SOLE DISCRETION.

If we terminate or suspend your account for any reason, you are prohibited fromregistering and creating a new account under your name, a fake or borrowed name,or the name of any third party, even if you may be acting on behalf of the third party.In addition to terminating or suspending your account, we reserve the right to takeappropriate legal action, including without limitation pursuing civil, criminal, andinjunctive redress.

 

  1. MODIFICATIONS AND INTERRUPTIONS

We reserve the right to change, modify, or remove the contents of the Services at anytime or for any reason at our sole discretion without notice. However, we have noobligation to update any information on our Services. We will not be liable to you orany third party for any modification, price change, suspension, or discontinuance of the Services.

We cannot guarantee the Services will be available at all times. We may experiencehardware, software, or other problems or need to perform maintenance related to theServices, resulting in interruptions, delays, or errors. We reserve the right to change,revise, update, suspend, discontinue, or otherwise modify the Services at any time orfor any reason without notice to you. You agree that we have no liability whatsoeverfor any loss, damage, or inconvenience caused by your inability to access or use theServices during any downtime or discontinuance of the Services. Nothing in theseLegal Terms will be construed to obligate us to maintain and support the Services orto supply any corrections, updates, or releases in connection therewith.

 

  1. GOVERNING LAW

These Legal Terms are governed by and interpreted following the laws of the United Kingdom, and the use of the United Nations Convention of Contracts for the International Sales of Goods is expressly excluded. If your habitual residence is in the EU, and you are a consumer, you additionally possess the protection provided to you by obligatory provisions of the law in your country to residence. GMP Property Services and yourself both agree to submit to the non-exclusive jurisdiction of the courts of __________, which means that you may make a claim to defend your consumer protection rights in regards to these Legal Terms in the United Kingdom, orin the EU country in which you reside.

 

  1. DISPUTE RESOLUTION

Informal Negotiations

To expedite resolution and control the cost of any dispute, controversy, or claimrelated to these Legal Terms (each a ‘Dispute’ and collectively, the ‘Disputes’) broughtby either you or us (individually, a ‘Party’ and collectively, the ‘Parties’), the Partiesagree to first attempt to negotiate any Dispute (except those Disputes expressly provided below) informally for at least thirty (30) days before initiating arbitration. Such informal negotiations commence upon written notice from one Party to the other Party.

Binding Arbitration

Any dispute arising from the relationships between the Parties to these Legal Termsshall be determined by one arbitrator who will be chosen in accordance with the Arbitration and Internal Rules of the European Court of Arbitration being part of the

European Centre of Arbitration having its seat in Strasbourg, and which are in forceat the time the application for arbitration is filed, and of which adoption of this clause constitutes acceptance. The seat of arbitration shall be London, United Kingdom. The language of the proceedings shall be English. Applicable rules of substantive law shall be the law of the United Kingdom.

Restrictions

The Parties agree that any arbitration shall be limited to the Dispute between theParties individually. To the full extent permitted by law, (a) no arbitration shall bejoined with any other proceeding; (b) there is no right or authority for any Dispute to be arbitrated on a class-action basis or to utilise class action procedures; and (c)there is no right or authority for any Dispute to be brought in a purported representative capacity on behalf of the general public or any other persons.

Exceptions to Informal Negotiations and Arbitration

The Parties agree that the following Disputes are not subject to the above provisions concerning informal negotiations binding arbitration: (a) any Disputes seeking to enforce or protect, or concerning the validity of, any of the intellectual property rights of a Party; (b) any Dispute related to, or arising from, allegations of theft, piracy, invasion of privacy, or unauthorised use; and (c) any claim for injunctive relief. If this provision is found to be illegal or unenforceable, then neither Party will elect to arbitrate any Dispute falling within that portion of this provision found to be illegal or unenforceable and such Dispute shall be decided by a court of competent jurisdiction within the courts listed for jurisdiction above, and the Parties agree to submit to the personal jurisdiction of that court.

 

  1. CORRECTIONS

There may be information on the Services that contains typographical errors, inaccuracies, or omissions, including descriptions, pricing, availability, and various other information. We reserve the right to correct any errors, inaccuracies, or omissions and to change or update the information on the Services at any time, without prior notice.

 

  1. DISCLAIMER

THE SERVICES ARE PROVIDED ON AN AS-IS AND AS-AVAILABLE BASIS. YOUAGREE THAT YOUR USE OF THE SERVICES WILL BE AT YOUR SOLE RISK. TOTHE FULLEST EXTENT PERMITTED BY LAW, WE DISCLAIM ALL WARRANTIES,EXPRESS OR IMPLIED, IN CONNECTION WITH THE SERVICES AND YOUR USETHEREOF, INCLUDING, WITHOUT LIMITATION, THE IMPLIED WARRANTIES OFMERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, AND NON-INFRINGEMENT. WE MAKE NO WARRANTIES OR REPRESENTATIONS ABOUTTHE ACCURACY OR COMPLETENESS OF THE SERVICES’ CONTENT OR THECONTENT OF ANY WEBSITES OR MOBILE APPLICATIONS LINKED TO THESERVICES AND WE WILL ASSUME NO LIABILITY OR RESPONSIBILITY FORANY (1) ERRORS, MISTAKES, OR INACCURACIES OF CONTENT ANDMATERIALS, (2) PERSONAL INJURY OR PROPERTY DAMAGE, OF ANY NATUREWHATSOEVER, RESULTING FROM YOUR ACCESS TO AND USE OF THESERVICES, (3) ANY UNAUTHORISED ACCESS TO OR USE OF OUR SECURESERVERS AND/OR ANY AND ALL PERSONAL INFORMATION AND/ORFINANCIAL INFORMATION STORED THEREIN, (4) ANY INTERRUPTION ORCESSATION OF TRANSMISSION TO OR FROM THE SERVICES, (5) ANY BUGS,VIRUSES, TROJAN HORSES, OR THE LIKE WHICH MAY BE TRANSMITTED TOOR THROUGH THE SERVICES BY ANY THIRD PARTY, AND/OR (6) ANY ERRORSOR OMISSIONS IN ANY CONTENT AND MATERIALS OR FOR ANY LOSS ORDAMAGE OF ANY KIND INCURRED AS A RESULT OF THE USE OF ANYCONTENT POSTED, TRANSMITTED, OR OTHERWISE MADE AVAILABLE VIATHE SERVICES. WE DO NOT WARRANT, ENDORSE, GUARANTEE, OR ASSUMERESPONSIBILITY FOR ANY PRODUCT OR SERVICE ADVERTISED OROFFERED BY A THIRD PARTY THROUGH THE SERVICES, ANY HYPERLINKEDWEBSITE, OR ANY WEBSITE OR MOBILE APPLICATION FEATURED IN ANYBANNER OR OTHER ADVERTISING, AND WE WILL NOT BE A PARTY TO OR INANY WAY BE RESPONSIBLE FOR MONITORING ANY TRANSACTION BETWEENYOU AND ANY THIRD-PARTY PROVIDERS OF PRODUCTS OR SERVICES. ASWITH THE PURCHASE OF A PRODUCT OR SERVICE THROUGH ANY MEDIUMOR IN ANY ENVIRONMENT, YOU SHOULD USE YOUR BEST JUDGEMENT ANDEXERCISE CAUTION WHERE APPROPRIATE.

 

  1. LIMITATIONS OF LIABILITY

IN NO EVENT WILL WE OR OUR DIRECTORS, EMPLOYEES, OR AGENTS BE LIABLE TO YOU OR ANY THIRD PARTY FOR ANY DIRECT, INDIRECT,CONSEQUENTIAL, EXEMPLARY, INCIDENTAL, SPECIAL, OR PUNITIVE DAMAGES, INCLUDING LOST PROFIT, LOST REVENUE, LOSS OF DATA, OR OTHER DAMAGES ARISING FROM YOUR USE OF THE SERVICES, EVEN IF WE

HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

NOTWITHSTANDING ANYTHING TO THE CONTRARY CONTAINED HEREIN,OUR LIABILITY TO YOU FOR ANY CAUSE WHATSOEVER AND REGARDLESSOF THE FORM OF THE ACTION, WILL AT ALL TIMES BE LIMITED TO

THEAMOUNT PAID, IF ANY, BY YOU TO US

DURING THE SIX (6) MONTH PERIODPRIOR TO ANY CAUSE OF ACTION ARISING. CERTAIN US STATE LAWS ANDINTERNATIONAL LAWS DO NOT ALLOW LIMITATIONS ON IMPLIEDWARRANTIES OR THE EXCLUSION OR LIMITATION OF CERTAIN DAMAGES. IFTHESE LAWS APPLY TO YOU, SOME OR ALL OF THE ABOVE DISCLAIMERS ORLIMITATIONS MAY NOT APPLY TO YOU, AND YOU MAY HAVE ADDITIONALRIGHTS.

 

  1. INDEMNIFICATION

You agree to defend, indemnify, and hold us harmless, including our subsidiaries, affiliates, and all of our respective officers, agents, partners, and employees, from and against any loss, damage, liability, claim, or demand, including reasonable attorneys’ fees and expenses, made by any third party due to or arising out of:

(1)your Contributions; (2) use of the Services; (3) breach of these Legal Terms; (4) any breach of your representations and warranties set forth in these Legal Terms; (5) your violation of the rights of a third party, including but not limited to intellectual property rights; or (6) any overt harmful act toward any other user of the Services with whom you connected via the Services. Notwithstanding the foregoing, we reserve the right, at your expense, to assume the exclusive defense and control of any matter for which you are required to indemnify us, and you agree to cooperate, at your expense, with our defense of such claims. We will use reasonable efforts to notify you of any such claim, action, or proceeding which is subject to this indemnification upon becoming aware of it.

 

  1. USER DATA

We will maintain certain data that you transmit to the Services for the purpose of managing the performance of the Services, as well as data relating to your use of the Services. Although we perform regular routine backups of data, you are solely responsible for all data that you transmit or that relates to any activity you have undertaken using the Services. You agree that we shall have no liability to you for any loss or corruption of any such data, and you hereby waive any right of action against us arising from any such loss or corruption of such data.

 

  1. ELECTRONIC COMMUNICATIONS, TRANSACTIONS,AND SIGNATURES

Visiting the Services, sending us emails, and completing online forms constitute electronic communications. You consent to receive electronic communications, and you agree that all agreements, notices, disclosures, and other communications we provide to you electronically, via email and on the Services, satisfy any legal requirement that such communication be in writing. YOU HEREBY AGREE TO THEUSE OF ELECTRONIC SIGNATURES, CONTRACTS, ORDERS, AND OTHERRECORDS, AND TO ELECTRONIC DELIVERY OF NOTICES, POLICIES, ANDRECORDS OF TRANSACTIONS INITIATED OR COMPLETED BY US OR VIA THESERVICES. You hereby waive any rights or requirements under any statutes, regulations, rules, ordinances, or other laws in any jurisdiction which require an original signature or delivery or retention of non-electronic records, or to payments or the granting of credits by any means other than electronic means.

 

  1. MISCELLANEOUS

These Legal Terms and any policies or operating rules posted by us on the Services or in respect to the Services constitute the entire agreement and understanding between you and us. Our failure to exercise or enforce any right or provision of these Legal Terms shall not operate as a waiver of such right or provision. These Legal Terms operate to the fullest extent permissible by law. We may assign any or all of our rights and obligations to others at any time. We shall not be responsible or liable for any loss, damage, delay, or failure to act caused by any cause beyond our reasonable control. If any provision or part of a provision of these Legal Terms is determined to be unlawful, void, or unenforceable, that provision or part of the provision is deemed severable from these Legal Terms and does not affect the validity and enforceability of any remaining provisions. There is no joint venture, partnership, employment or agency relationship created between you and us as result of these Legal Terms or use of the Services. You agree that these Legal Terms will not be construed against us by virtue of having drafted them. You hereby waive any and all defenses you may have based on the electronic form of these Legal Terms and the lack of signing by the parties hereto to execute these Legal Terms.

 

  1. CONTACT US

In order to resolve a complaint regarding the Services or to receive further information regarding use of the Services, please contact us at:

 

GMP Property Services

71-75 Shelton Street Covent Garden

London

United Kingdom

Phone: 02034888198 | 07479566650

[email protected]